File #: 190419    Version: Name:
Type: Ordinance Status: Passed
File created: 9/30/2019 In control: Village Board of Trustees
On agenda: Final action: 11/5/2020
Title: PC 19-22: International Village Signage, 1300-1366 S. Finley Road - Time Extension Requesting approval of an ordinance extending the time period to start construction of the proposed project for an additional twelve-month period until November 7, 2021. The petitioner requests a waiver of first reading. (DISTRICT #2)
Attachments: 1. 190419_IDRC Report PC 19-22 1300-1366 S Finley International Village Signage, 2. 190419_Cover Sheet PC 19-22 1300-1366 S Finley Rd International Village Sign, 3. Ordinance 7743 PC 19-22 International Village Signage 1300-1366 S Finley Rd.pdf, 4. Cover Page 190419.pdf, 5. Ordinance 7743 Recorded.pdf, 6. BOARD MEETING 11-5-20 190419_PC 19-22 International Village Sign 1300 S Finley Time Extension, 7. Ordinance 7877 PC 19-22 Internatonal Village Signage 1300-1366 S Finley Rd - Time Extension.pdf, 8. Cover Page 190419.pdf, 9. Ordinance 7877 Recorded.pdf
Date Ver.Action ByActionResultAction DetailsMeeting DetailsVideo
2/16/20213 Recorder Recorded  Action details Meeting details Not available
11/5/20203 Village Board of Trustees waived of first reading and passed on second reading with suspension of the rulesPass Action details Meeting details Not available
1/16/20202 Recorder Recorded  Action details Meeting details Not available
11/7/20192 Village Board of Trustees waived of first reading and passed on second reading with suspension of the rulesPass Action details Meeting details Not available
10/21/20191 Plan Commission recommended to the Corporate Authorities for approval subject to conditionsPass Action details Meeting details Video Video

Title

PC 19-22: International Village Signage, 1300-1366 S. Finley Road - Time Extension

Requesting approval of an ordinance extending the time period to start construction of the proposed project for an additional twelve-month period until November 7, 2021.  The petitioner requests a waiver of first reading. (DISTRICT #2)

Body

[Enter body here.]