File #: 210016    Version: Name:
Type: Ordinance Status: Passed
File created: 1/4/2021 In control: Village Board of Trustees
On agenda: Final action: 2/16/2023
Title: PC 21-08 Car Wash, 352 E. Roosevelt Road Time Extension The petitioner requests is requesting approval of an Ordinance extending the time period to start construction of the proposed project for an additional twelve-month period until March 4, 2024. (DISTRICT #6)
Attachments: 1. 210016_PC 21-08 352 E Roosevelt Road - Car Wash, 2. BOARD MEETING 2-18-21 210016_PC 21-08 2 of 2 Attachments -LOWER RES, 3. BOARD MEETING 2-18-21 210016_PC 21-08 1 of 2 Car Wash 352 E Roosevelt Road, 4. Ordinance 7930 PC 21-08 Car Wash - 352 E Roosevelt Rd.pdf, 5. Cover Page 210016.pdf, 6. Ordinance 7930 Recorded.pdf, 7. BOARD MEETING 02-16-23 210016 PC 21-08 352 E Roosevelt Road - Time Extension, 8. Ordinance 8127 PC 21-08 Car Wash 352 E Roosevelt Road Time Extension.pdf, 9. Cover Page 210016.pdf, 10. Ordinance 8127 Recorded.pdf
Date Ver.Action ByActionResultAction DetailsMeeting DetailsVideo
5/9/20233 Recorder Recorded  Action details Meeting details Not available
2/16/20233 Village Board of Trustees waived of first reading and passed on second reading with suspension of the rulesPass Action details Meeting details Not available
6/1/20212 Recorder Recorded  Action details Meeting details Not available
3/4/20212 Village Board of Trustees passed on second readingPass Action details Meeting details Not available
2/18/20212 Village Board of Trustees passed on first readingPass Action details Meeting details Not available
1/25/20211 Plan Commission recommended to the Corporate Authorities for approval subject to conditionsPass Action details Meeting details Video Video

Title

PC 21-08 Car Wash, 352 E. Roosevelt Road Time Extension

The petitioner requests is requesting approval of an Ordinance extending the time period to start construction of the proposed project for an additional twelve-month period until March 4, 2024.  (DISTRICT #6)

Body

[Enter body here.]